The Times - Serving Waitsburg, Dayton and the Touchet Valley


The Times 

Legals - February 2, 2018

 

February 1, 2018



Waitsburg School District

INVITATION TO BID

WAITSBURG SCHOOL DISTRICT

184 Academy Street

Waitsburg, WA 99361

509-337-6301

DESIGN WEST ARCHITECTS

254 E. Main Street

Pullman, WA 99163

509-332-3113

You are invited to bid on a General Contract for construction in the City of Waitsburg for the improvements to each school building as defined in the construction documents. The project consists of new HVAC and kitchen renovations at the elementary school, new HVAC renovations at the middle school, new HVAC renovations at the high school and a new field house building at the football field consisting of approximately 1,700 square feet, including Site Work, Structures, Finishes, Fire Protection, Mechanical, and Electrical work at all buildings.

Preliminary Estimate:

Base Bid – Elementary School & Field House: $2,570,000

Alternate #1 – High School Auditorium: $ 350,000

Alternate #2 – Masonry at Field House: $ 20,000

Alternate #3 – High School Lower Level HVAC $ 280,000

Alternate #4 – Preston Hall HVAC $ 270,000

Proposals will be accepted by the District until 3:00 PM, prevailing time, on Thursday, March 1, 2018 at the Waitsburg School District Building at 184 Academy Street, Waitsburg, WA. Bid proposals will be opened publicly and read aloud at 3:00pm. Interested parties are invited to attend.

A Pre-Bid Conference, optional for all General Contractor prospective bidders, will be held Tuesday, February 20, 2018 at 10:30 AM at the project site, 184 Academy Street, Waitsburg, WA.

Plans and Specifications are available, beginning Monday, February 5, 2017, through the Architect.

E-mailed PDF drawings and specifications are available at no cost (highly encouraged). Printed paper sets are available at $200 per set. The cost is refundable provided the documents are returned in good condition within 10 days after bid opening to the office of the Architect. Contact Chelsea Holstad, Office Manager with Design West Architects by e-mail at cholstad@designwestpa.com to request documents.

Bid security amounting to five percent (5%) of the total Base Bid must accompany each Bidder’s proposal in accordance with Instructions to Bidders.

Bid documents will be available for examination during the bidding period at the following locations:

Associated Builders & Contractors, Inc. – Spokane Valley, WA

Abadan Regional Plan Center – Spokane, WA

Hermiston Plan Center – Hermiston, OR

Spokane Regional Plan Center – Spokane, WA

Tri-City Construction Council – Kennewick, WA

Walla Walla Valley Plan Center – Walla Walla, WA

Yakima Plan Center – Yakima, WA

No bidder may withdraw his proposal after the date and time set for opening thereof or before Award of Contract, unless said award is delayed beyond 30 days. Substantial Completion shall be achieved in compliance with Section 01 10 00 of the project specifications.

The project requires compliance with prevailing wage under RCW 39.12 and apprenticeship participation of 15% under RCW 39.04.320.

The District reserves the right to accept or reject any or all proposals, and in particular, to reject a proposal not accompanied by the required bid security or data required. The process shall comply with WAC 180-29-105, RCW 28A.335.190 and RCW 43.19.1906.

The Times

Feb. 1, 8, 2018

2-1-e

--------------------

ADVERTISEMENT FOR BIDS

Columbia County, Washington, invites bids for a 2018 or newer Rock Rake. Specifications and bid packages are available from the Columbia County Public Works Department, P.O. Box 5, 415 N. Guernsey Ave, Dayton, Washington 99328 or from the County website at http://www.ColumbiaCo.com . Sealed bids will be received by Columbia County at the Columbia County Public Works Department until 3:30pm on Friday, February 16, 2018. Bids delivered in person will be received only at the reception desk of said office.

Bids will be publicly opened at the Columbia County Commissioners Chambers at 341 East Main St. Dayton, Washington after 10:00am on Tuesday February 20, 2018.

The Times

Feb. 1, 8, 2018

2-1-a

---------------------

Case No. 18-4-00012-1

NOTICE TO CREDITORS

(RCW 11.40.030)

IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON

IN AND FOR THE COUNTY OF WALLA WALLA

In Re the Estate

of

GAYLEY SHATTUCK WILSON

Deceased.

The Co-Personal Representatives named below have been appointed and have qualified as Co-Personal Representatives of this estate. Any person having a claim against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the Co-Personal Representatives or the Co-Personal Representatives’ attorney at the address stated below, a copy of the claim and filing the original of the claim with the Court. The claim must be presented within the later of: (1) Thirty days after the Co-Personal Representatives served or mailed the notice to the creditor as provided under RCW 11.40.020(3); or (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and RCW 11.40.060. This bar is effective as to claims against both the decedent’s probate and non-probate assets.

Date of filing copy of Notice to Creditors: 01/23/2018

Date of First Publication: 02/01/2018

/s/ KAREN LANGERT

Co-Personal Representative

/s/ JULIE WILSON

Co-Personal Representative

The Times

Feb, 1, 8, 15, 2018

2-1-b

---------------------

Notice of Public Hearing

Notice is hereby given that a public hearing has been established for Monday,

February 5, 2018 at 11:00 am in the Columbia County Commissioners office to

hear comments on the proposed 2018 Columbia County Fairgrounds and Golf

Course Fee Schedules. Copies of the proposed fee schedules are available for

inspection at the Columbia County Commissioner’s office during regular business

hours.

Approval is pending this hearing.

By Order of the Columbia County Board of Commissioners.

Leanne J. Peters

Clerk of the Board

The Times

Jan. 25, Feb 1, 2018

1-25-a

--------------------

No: 17-7-00210-0

Notice and Summons by Publication

Dependency

X Termination

(SMPB)(Optional Use)

Superior Court of Washington

County of Walla Walla

Juvenile Court

In Re the Termination of:

WEIS, Owen Nathaniel Elijah

D.O.B .: 08/09/2016

To: EMILIE MICHELLE DELAROSA, Mother

JONATHON STEPHEN WEIS, Alleged Father

JOHN DOE

A Termination Petition was filed on December 18, 2017; a Fact Finding hearing will be held on this matter on: March 2, 2018, at 9:30 AM, at Walla Walla County Superior Court, 315 W. Main St., Walla Walla WA, Department I. You should be present at this hearing.

The hearing will determine if your parental rights to your child will be terminated. If you do not appear at the hearing, the court may enter an order resulting in permanent loss of your parental rights in your absence.

To request a copy of the Notice, Summons, and Termination Petition, call DSHS at (509) 524-4900. To view information about your rights, including right to a lawyer, go to http://www.atg.wa.gov/TRM.aspx

Dated: Jan. 18, 2018

Issued by Petitioner:

/s/ Michelle M. Mulhern

Michelle M. Mulhern, WSBA# 23185

Deputy Prosecuting Attorney

The Times

Jan. 25, Feb. 1, Feb. 8, 2018

1-25-d

------------------------

No. 17-4-00220-6

PROBATE NOTICE TO CREDITORS

IN THE SUPERIOR COURT OF WASHINGTON

IN AND FOR THE COUNTY OF WALLA WALLA

In Re the Estate of

VERLE ARLINE DEVINE,

Deceased.

The Personal Representative named below has been appointed as Personal Representative of this estate. Any person having a claim against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the Personal Representative or the Personal Representative’s attorney stated below a copy of the claim and filing of the original of the claim with the court in which the probate proceedings were commenced. The claim must be presented within the later of: (1) Thirty days after the Personal Representative served or mailed the notice to the creditor as provided under RCW 11.40.020(1)(c); or (2) four months after the date of first publication of the notice.

If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the decedent’s probate and nonprobate assets.

Personal Representative: MARK DUNKEL

Date of First Publication: February 1, 2018

/s/ Mark Dunkel

MARK DUNKEL

Personal Representative of the

Estate of VERLE ARLINE DEVINE

Attorney for the Personal Representative and address for mailing and service:

David S. Grossman

Minnick-Hayner, P.S.

P.O. Box 1757

249 West Alder

Walla Walla, WA 99362

Publish: 2/1/2018, 2/8/2018, 2/15/2018

Court of Probate Proceedings and Cause Number:

Walla Walla County Superior Court

Cause No .: 17-4-00220-6

The Times

Feb. 1, 8, 15, 2018

2-1-d

-------------------------

OFFICIAL CALL FOR BIDS

NOTICE IS HEREBY GIVEN

That sealed bids will be received at the Waitsburg City Hall, 147 Main Street, P.O. Box 35, Waitsburg, WA 99361, until 2:00 p.m. on Friday, February 9, 2018 for the following:

1992 Kubota FZ2100 Commercial Mower with 3239 hrs

Sealed bids will be opened and publicly read at 2 p.m. or soon thereafter on Friday, February 9, 2018 at Waitsburg City Hall, 147 Main Street, Waitsburg, WA 99361 with the surplus mower going to the highest bidder.

A minimum bid of $250 is required. Additional information is available by contacting Waitsburg City Hall, 147 Main Street, Waitsburg, WA 99361. Bids will be taken based upon the condition of the vehicle being ‘as is’ with no warranty nor guarantee. The mower can be viewed at the City of Waitsburg’s Public Works Shop at 128 Coppei or by appointment by contacting Waitsburg City Hall.

The Waitsburg City Administrator reserves the right to accept or reject any or all bids submitted and to waive any informality in the bids.

Bids must be sealed and plainly marked “sealed bid”.

Randy Hinchliffe

City Administrator

The Times

Feb. 1, 2018

2-1-g

-------------------------

STATE OF WASHINGTON

Material Lease Changes

The Department of Natural Resources (DNR) has commenced the process of amending material terms and conditions of Dryland Lease No. 12-E56223 leased to Greg Fletcher and described as All of Section 16, Township 9 North, Range 33 East, W.M., Walla Walla County containing 640 acres. The specific change(s) returning CRP ground back to dryland agriculture production and extending the term of the lease to expire August 31, 2027. Comments may be addressed to DNR Southeast Region Office, 713 Bowers Rd, Ellensburg, WA 98926, or by calling (509) 925-8510. Comments must be received by February 12, 2018

Hillary Franz, Commissioner of Public Lands

The Times

Feb. 1, 2018

2-1-c

---------------------------

NOTICE OF APPLICATION

COLUMBIA COUNTY SHORELINES-SUBSTANTIAL DEVELOPMENT PERMIT

Columbia County Planning and Building hereby gives notice per WAC 173-27-110 that the Department has received a complete Shorelines Substantial Development Permit Application from Columbia County Public Works for the following project:

APPLICANT: Columbia County Public Works, PO Box 5, Dayton, Washington 99328. Contact Andrew Woods, Columbia County Engineer, 509-382-2534

PROJECT LOCATION: Vernon Smith Bridge on Rose Gulch Road, unincorporated Columbia County, Washington, T: 9N, R: 38E, S: 3.

APPLICATION RECEIVED: The application was received on January 29th, 2018, and was deemed complete on January 30th, 2018.

PROPOSAL: To rebuild the Vernon Smith Bridge and realign Rose Gulch Road in unincorporated Columbia County, Washington. The new Vernon Smith Bridge will cross the Touchet River approximately 250 feet upstream from the existing crossing. Improvements will include realignment of Rose Gulch Road, and replacing the existing 165’ long bridge with a 135’ long bridge. The application included the Shorelines Substantial Development Permit, the SEPA DNS (below), and a completed JARPA. All application materials are available for review at the below address.

SEPA: A Determination of Non-Significance was issued by Columbia County Public Works (lead agency for the project) on January 19, 2018. The application included the DNS and completed SEPA Checklist.

ADDITIONAL PERMITTING: At this time, no additional environmental permits are required per review of the completed JARPA.

REQUESTS FOR COMMENTS: The Department of Planning and Building hereby requests written comments for the above described project. Written comments can be submitted by the following methods: In person at 114 South 2nd Street, Dayton, Washington 99328 or via email to Meagan_bailey@co.columbia.wa.us. Written comments must be submitted no later than March 2nd, 2018.

The Times

Feb.1, 2018

2-1-f

-----------------------

File No. HO17-009

NOTICE OF APPLICATION

The application described below has been submitted to the Walla Walla County Community Development Department (CDD).

File name/Docket #: Type 2 Home Occupation Lawn Care Company/HO17-009

Application type: HOME OCCUPATION, TYPE 2

Applicant: ROQUE DIAZ

PO BOX 430

WALLA WALLA WA, 99362

Property Owner: CISNEROS, LARA MARIA NANCY

PO BOX 430

WALLA WALLA WA, 99362

Project description: Home Occupation consisting of equipment storage for a lawn care company. A company truck and trailer will be parked in the garage or driveway and lawn care equipment will be stored in the garage. No non-resident employees will be employed on site. The property is zoned Agriculture Residential 10-acres (AR-10). The site is generally located at 4531 S Highway 125 (APN # 350611440048).

Required Permits: None identified

Development Regulations: WWCC 17.08.261

Date of application: 12/7/2017

Date determined complete: 01/19/2018

Date of notice: 02/01/2018

  

REVIEW PROCESS AND PUBLIC COMMENT: The decision on this application will be made by the CDD Director. The comment period for this project is fourteen (14) days from issuance of this notice; this period ends February 15, 2018. The notice of application is required by RCW 36.70B.110 and Walla Walla County Code (WWCC) 14.07.080.

To be considered as a party of record send written comments to:

Walla Walla County Community Development Department

c/o Don Sims, Associate Planner

310 W. Poplar Street, Suite 200

Walla Walla, WA 99362

commdev@co.walla-walla.wa.us

APPEALS: The Director’s decision may be appealed by the applicant(s) or parties of record to the Walla Walla County Hearing Examiner pursuant to WWCC 14.11.010 and 14.11.030.

FOR MORE INFORMATION: Please contact Don Sims, Associate Planner, at 509-524-2618 or commdev@co.walla-walla.wa.us.

The Times

Feb. 1, 2018

2-1-h

 

Reader Comments
(0)

 
 

Powered by ROAR Online Publication Software from Lions Light Corporation
© Copyright 2018

Rendered 01/05/2019 20:45